A.      DEFINITIONS


A.01        Agreement:  The agreement between the Client and the Architect consisting of Parts 01, 02, 03 and 04 of this document and all attachments listed.

A.02        Architect:  The person, company or firm identified as the Architect in Part 01 of this Agreement.

A.03        Brief: Statements and materials assembled by the Client with the Architect’s assistance to summarise the Client’s initial requirements, to address the Client’s preferences

                and priorities, and to summarise the impact of context, environment and prevailing legislation at the time of signing this Agreement.

A.04        Client:  The person, company or firm identified as the Client in Part 01 of this Agreement.

A.05        Construction Cost:  The latest professionally prepared estimate for the final cost of constructing all elements of the Project designed or specified by the Architect, including:

                –  Any contingencies for changes in work or design reserve cost allowances,

                –  The cost of any equipment and/or materials provided (as if new) or to be provided by the Client to a contractor for installation during construction of the Project,

                –  Any direct costs carried out by, or on behalf of, the Client,

                –  Provision for contractor’s profit and overheads.

                The Construction Cost shall not include:

                –  GST,

                –  Design fees,

                –  Cost of the land,

                –  Any loss and/or expense payments paid to a contractor,

                –  Any liquidated damages deducted by the Client,

                –  The costs of resolution of any dispute,

                –  The Client’s legal and in-house expenses.

A.06        Consultant:  A person, company or firm appointed by the Client to perform professional services in connection with the Project.

A.07        Fee Proposal:  The fee structure set out in Part 02 of this Agreement that is payable to the Architect as agreed by the Client and the Architect.

A.08        Hourly Rates:  The hourly charge-out rates of the Architect set out in section G of Part 02 of this Agreement.

A.09        Project:  The project identified in Part 01 of this Agreement, more specifically detailed in section C of Part 02 of this Agreement.

A.10        Project Schedule:  The period of time agreed by the Client and the Architect for completion of the Services as set out in section E of Part 02 of this Agreement.

A.11        Services:  The Services to be performed by the Architect as specified in the Part 03 of

                this Agreement. Services may be varied by the Client in accordance with this Agreement.

A.12        Site:  The premises where the Works are to be carried out.

A.13        The Design:  The Design means design concepts, drawings and documents provided under this agreement.  The Architect retains copyright in The Design as set out in

                Clause F.01.

A.14        Works:  Any permanent or temporary structure, building, fixture or access constructed or required to be constructed on the Site as part of the Project.

 

 

B.      ARCHITECT’S OBLIGATIONS


B.01        The Client and the Architect shall work together in a spirit of mutual trust and cooperation. In relation to the Services, either party shall advise the other upon becoming

                aware of:

B.01.01   A need to vary the Services, the Project Schedule or Construction Cost, the fees and/or any other part of this Agreement

B.01.02   Any incompatibility with any of the Client’s requirements in the Brief or between the Brief, any Client’s instructions, the Construction Cost, the Project Schedule and/or the

                approved design or any need to vary any part thereof

B.01.03   Any information or decisions required from the Client or others in connection with the performance of the Services

B.01.04   A need to appoint consultants or other persons to design or carry out any part of the Works or to provide specialist advice or additional inspection services in connection with

                the Project, and the parties shall agree how to deal with the matter.

B.02        The Architect shall provide the Services set forth in this Agreement exercising a reasonable level of skill and care ordinarily provided by architects practicing in the same or

                similar locality under the same or similar circumstances.

B.03        The Architect shall perform the Services with due regard to any schedule, including the Project Schedule, and/or budget agreed with the Client. Notwithstanding the

                aforesaid, the Architect does not warrant that the Services or the Project will be completed in accordance with any such schedule or budget, nor does the Architect

                warrant that approvals from third parties will be granted.

B.04        The Architect shall notify the Client in writing when an instruction from the Client or any other requirement changes the Scope of Services or requires Services not

                provided for by this Agreement.

 

 

C.      CLIENT’S OBLIGATIONS


C.01        The Client shall supply the Architect with the Brief and shall advise the Architect of the relative priorities of the Brief, the Construction Cost and the Project Schedule by way of

                meetings and written directions or communications as necessary to ensure complete understanding of such Project priorities by the Architect.

C.02        The Client will directly appoint all other consultants required by the Project which may include, but is not limited to: cost consultant, landscape architect, engineers and

                surveyors. The Client will require that said Consultants maintain professional liability insurance as appropriate to the services provided. Upon the Architect’s request the Client

                shall furnish the Architect with copies of the Consultant’s scope of service.

C.03        The Client shall directly appoint the contractor and where required subcontractors and require that said contractor and subcontractors maintain professional liability insurance

                as appropriate to the services provided. Upon the Architect’s request, the Client shall furnish the Architect with copies of the contractor’s and subcontractors’ scope of service.

C.04        The Client shall hold each such consultant / subconsultant / contractor / subcontractor, however appointed, and not the Architect, responsible for the proper performance of

                their services and shall require such other party(s) to cooperate with the Architect to enable the Architect to properly and effectively perform the Services.

C.05        Where decisions are required of the Client, such decisions shall be given in a reasonable time to the Architect to enable the Architect to perform the Services properly and

                in a timely manner.

C.06        The Client shall commit adequate resources to the Project to enable the Architect to perform the Services properly and in a timely manner.

C.07        The Client shall pay in accordance with Clause D, all fees due plus GST for the Services and

                Expenses specified in this Agreement, and any subsequently required Services or Expenses, and pay interest on overdue amounts.

C.08        The Client shall allow the Architect reasonable access to photograph or otherwise record the Project before and/or after completion.

 

 

D.      FEES


D.01        The Client must pay to the Architect, in accordance with Part 02 of this Agreement, all fees due plus applicable taxes and expenses as specified in Part 02 of this Agreement.

                The Fee Proposal is based on the Project Schedule stated therein. If the Services covered by this Agreement have not been completed within the period allowed under the

                Project Schedule through no fault of the Architect, an extension of the Architect’s Services beyond that time shall be compensated as additional services and chargeable by

                the Architect on an hourly basis at the Hourly Rates.

D.02        In addition, the Fee Proposal covers only the Services set out in Part 03 of this Agreement.  Any additional services required to be performed by the Architect over and above

                such Services shall also be chargeable on an hourly basis at the Hourly Rates. The Architect shall advise the Client as soon as practicable that additional services have been, or

                are being, carried out and that, as a consequence, additional fees are payable.

D.03        All fees are to be paid within 7 days of invoice. Amounts due under an invoice and not paid within the period stated above will be subject to interest at a rate of 10% per annum.

                Interest will be applied pro rata on the outstanding balance by dividing the rate by 365 to obtain a daily rate and multiplying that percentage by the number of days the

                balance is overdue. If the fees are not cleared in the Architect’s bank account by the due date, the Architect does not guarantee to continue to provide the Services.

D.04        Where, for any reason, the Architect provides only part of the Services set out in the Part 03 of the Agreement, the Architect shall be entitled to payment in full for all Services

                completed together with a fair and equitable proportion of the outstanding fee, to reflect the proportion of partial services completed.

 

 

E.      SET OFF


E.01        The Client may not deduct, reduce or withhold any payments due to the Architect under this Agreement by reason of claims or alleged claims against the Architect.

 

 

F.      COPYRIGHT AND LICENCE


F.01        The Architect retains copyright in all designs, drawings, models, plans, specifications, design details, photographs, brochures, reports, notes of meetings, CAD materials and

                any other materials provided by the Architect in connection with the Project (“the Materials”).

F.02        The Architect hereby grants, subject to payment of all outstanding fees, to the Client a non exclusive limited licence to use and reproduce the Materials for all purposes

                relating to the Project.

F.03        The Architect shall have no liability for any use of the Materials other than that for which the same were originally prepared and provided.

F.04        Such limited licence shall, in any case, not extend to the Client developing (whether itself or through a third party) any models or merchandise based on the Materials. Any such

                activity would be subject to separate terms, including an entitlement of the Architect to suitable royalties.

F.05        If the Architect rightfully terminates the Agreement for causes as specified in section K, the licence granted under section F will be revoked.

F.06        The architect shall not distribute AutoCAD files of the project, unless for the purpose of issue to engineering consultants for a current project that the architect is engaged, for

                use in a stage which the architect is engaged.  Other requests for documents shall be issued as .pdf files for the relevant stages.

 

 

G.      PUBLICITY


G.01        The Client shall, where required by the Architect and subject to section F above, in any publicity relating to the Project, credit the Architect as architect.

G.02        The Architect shall be entitled to royalties on any invention, new product or exploitation of any images arising out of the Services and/or the Materials.

G.03        The Architect shall have the right to publish photographs and information about the Project in its practice brochure and other promotional material.

 

 

H.      INSURANCE


H.01        The Architect shall take out and use reasonable endeavours to maintain the following insurances for the duration of the period of liability referred to in clause I.04:

H.01.01   Professional Indemnity Insurance in the sum of not less than $5,000,000

H.01.02   Public liability insurance in the sum of not less than $5,000,000

H.01.03   Insurance to cover liability to employees to statutory requirements (Worker’s Compensation).

 

 

I.        LIABILITY


To the maximum extent permitted by law:

I.01          Subject to the remaining clauses of this section,  the Architect’s total liability to the Client under this Agreement (including the performance or non-performance of the

                Services), whether under the law of contract, in tort, in equity, under statute or otherwise, is limited to the maximum amount (after deducting any excess payable) the Architect

                is entitled to recover under any of the contracts of insurance set out in section H in respect of any fact, matter or circumstance giving rise to the liability.

I.02         The extent of the Architect’s liability, whether in contract, in tort, in equity, under statute or otherwise, is reduced proportionately to the extent that the Client and/or any other

                person, including any third party, has contributed to the claim, liability, damage, loss or expense and irrespective of whether such contribution arises in contract, tort or

                otherwise.

I.03         If the Architect is liable to the Client, whether in contract, in tort, in equity, under statute or otherwise, the Architect will only be liable for any reasonable foreseeable and fully

                mitigated damage, loss or expense incurred by the Client, caused directly by a breach of the Architect’s legal obligations. The Architect has no liability to the Client in respect

                of any indirect, consequential or special losses (including loss of profit, loss of business, opportunity and payment of liquidated sums, or damages under any other agreement).

I.04         The Architect has no liability in respect to the Services after the expiration of 3 years from the completion of the Services subject to any compulsory limitation of action

                provisions which cannot by law be excluded or restricted in any contracts made between the parties.

I.05         In the circumstances where the Services (as described in Part 03 of this Agreement) are reduced, limited or varied by later agreement or the Agreement is terminated prior to

                the completion of the Services, the Architect’s liability will attach only to those services actually performed and then only to the extent that the reduction of that part of the

                Services has not compromised or not denied the Architect the opportunity to correct the performed services or to otherwise mitigate the Client’s loss.

I.06         The Architect is not liable for any damage, loss or expense incurred by the Client as a consequence of any change that the Client or any other person makes to the Architect’s

                construction documents, or from any variation to the Works from the Architect’s construction documents or any variation to the Project resource consent or the Project building

                consent, made without prior written notice to or approval by the Architect.

I.07         The Architect shall not be liable to any person other than the Client, and disclaims responsibility, in tort or otherwise, for any liability, damage, loss or expenses suffered or

                incurred by such person. In the event that the Project to which the Services relate is leased, transferred, sold, or otherwise disposed of in part or whole to other persons, then

                the Client warrants that such persons shall be advised in writing that the Architect accepts no responsibility in law to them. In the event of breach of this clause, the Client and

                in the case of a company, its directors, shall fully indemnify the Architect against any claim by such persons, whether such claim is in tort or otherwise.

I.08         The Client shall indemnify the Architect against the adverse effects of all claims including claims by third parties which arise out of or have a connection with this Agreement

                and are made after the expiry of the period of liability referred to in clause I.04 subject to any compulsory limitation of action provisions which cannot by law be excluded or

                restricted in any contracts made between the parties. For avoidance of doubt the indemnity includes claims in negligence made against the Architect.

I.09         The Client acknowledges that the Architect operates through employees, directors, officers, agents and sub-consultants and agrees that no reliance has or will be placed on

                them personally by the Client in connection with this Agreement on the performances of the Services.

I.10         The limitations of liability as described above will confer, to any extent relevant, a benefit on the employees, directors, officers, agents or sub-consultants of the Architect.

I.11          If any of these clauses is void as a result of any applicable legislation, or any regulations or rules promulgated thereunder, then the Architect’s liability for a breach of a

                condition or warranty is limited to the:

                –  Supplying of the relevant services again or

                –  Payment of the cost of having the relevant Services supplied again.

 

 

J.       ASSIGNMENT


J.01         Neither the Architect nor the Client shall assign the whole, nor any part, of the Agreement without the consent of the other in writing. Such consent shall not be unreasonably

                withheld.

 

 

K.      TERMINATION OR SUSPENSION


K.01        The Client may suspend the performance of any or all of the Services, by giving not less than 14 days notice to the Architect, specifying the service or services to be

                suspended.

K.02        The Architect may suspend performance of the Services and its obligations under this Agreement by giving 14 days notice to the Client of the intention to do so and the g

                rounds for doing so, in the event that the Client is in default of payment of any fees, or other amounts due, or is otherwise in default of its obligations hereunder. When the

                reason for the suspension is removed or resolved, the Architect shall resume performance of the Services and its obligations.

K.03        If any period of suspension arising from a valid notice served either by the Client on the Architect, or served by the Architect on the Client, exceeds 3 months, the Architect

                shall be entitled to treat this Agreement as being terminated with immediate effect.

K.04        The rights to terminate this Agreement shall not prejudice any other right or remedy of either party in respect of any breach or cause of action accrued at the date of

                termination.

K.05        On termination of this Agreement, unless otherwise agreed in writing:

K.05.01   The Client must:

                –  Pay the outstanding balance of all properly submitted invoices delivered prior to the notice,

                –  Pay the Architect for all services reasonably undertaken and any reimbursable expenses reasonably incurred by the architect since delivery of the notice.

K.05.02   The Architect must, on receipt of payment, issue to the Client a copy of The Design as it exists up to the date of termination.

 

 

L.      DISPUTE RESOLUTION


L.01        The parties shall seek to resolve any dispute or difference arising under this Agreement in good faith.

L.02        If the parties cannot resolve such dispute or difference within 14 days of either party serving notice on the other that a dispute has arisen, then either party may submit the

                dispute to mediation by delivering to the other a written proposal of mediation.

L.02.01   A proposal of mediation must state the name of the mediator accredited by an appropriate professional body in the state or territory of the law that applies; who is

                independent and willing to act.

L.03        If the parties are unable to agree on the choice of a mediator, or if the chosen mediator is unable or unwilling to act, then within 14 days after the proposal is delivered, the

                president of the chapter of the Institute of Arbitrators and Mediators Australia (IAMA) in the place of the law that applies, must be requested to nominate a mediator.

L.04        Any agreement between the parties shall be recorded in writing and, once signed by representatives of the parties, shall be binding on the parties.

L.05        The parties will bear their own costs of preparing and submitting evidence to the mediator. If the mediator finds that the mediation has been initiated or conducted frivolously

                or vexatiously then the mediator shall have the power to order the party so initiating or conducting the mediation to pay the reasonable costs of the other party for preparing

                for and attending the mediation. If such costs cannot be agreed, then these costs will be assessed by the mediator whose decision shall be binding on the parties.

L.06        If the parties are unable to resolve the dispute or difference by mediation, confirmed by the mediator in writing, either party may take legal action to resolve the dispute.

 

 

M.      GENERAL


M.01        The law applicable to this Agreement shall be the law of the state or territory of the Architect’s address stated in this Agreement.

M.02        The Architect shall be entitled to rely upon the accuracy and completeness of:

                –  The information furnished by the Client and

                –  The Client’s approvals.

M.03        The Architect is not responsible for ensuring the Project complies with the building contract documents, but when engaged for contract administration services, is required to

                instruct the building contractor regarding requirements of the building contract documents, according to the contract terms.

M.04        The Architect gives no express or implied warranty that the Project is fit for the Client’s purpose.

M.05        Any natural materials selected for the Project may change in appearance and dimension following exposure to use or climatic conditions and this is normal behaviour for such

                materials.

M.06        The scope of the Services does not include any services in relation to asbestos, other hazardous materials, or any other site contaminant.

M.07        Upon the completion of the Project, the Client is responsible for ongoing and regular maintenance of the Project, including its systems, finishes and equipment.

M.08        File keeping is the responsibility of the client and requests for documents following the completion of a stage shall be charged at an hourly rate for retrieval and distribution.

M.09        Nothing makes ineffective, or reduces, any protection at law from liability which the Architect is entitled to in the state of territory of the applicable law.

M.10        This Agreement supersedes all prior agreements relating to the Services for the Project, and does not apply to any services provided by the Architect before the formal

                execution of the Agreement.

 

 

N.      NOTICE OF DEFECTS


N.01        If, during the term of the Agreement or after completion of it, the Client becomes aware of any problem with the design, fault or defect in the Project, or non-compliance with

                the Project’s contract documents, the Client must promptly, but not later than 10 business days after becoming aware of it, notify the Architect about it in writing. If the Client

                does not do this, the Client will be treated as having waived any claim the Client may have against the Architect (in contract, tort or otherwise) in relation to the problem, fault or

                non- compliance.